Eprocure Procurement Opportunities and Guidelines

Procuring Authority

Eprocure

View Dossier

Consolidated Public Tender Opportunities & Work Package Directory

The following comprehensive schedule delineates all active procurement tenders and work contracts issued by Eprocure. Bidders must cross-verify specific NIT reference numbers, EMD requirements, and submission cutoff timestamps before compiling technical bid envelopes.

Technical Pre-Qualification Standards & Financial Solvency Criteria

Prospective contractors, original equipment manufacturers (OEMs), and authorized enterprise vendors seeking award of contracts under Eprocure must satisfy mandatory statutory pre-qualification gates as stipulated in the primary tender documents:

• Average Annual Financial Turnover: Bidders must demonstrate an average annual financial turnover during the preceding three financial years (ending March 31 of the previous fiscal period) of not less than 30% to 50% of the estimated tender value, substantiated by Chartered Accountant (CA) certified audited balance sheets bearing valid Unique Document Identification Numbers (UDIN).
• Similar Work Experience Benchmarks: Bidders must have successfully completed similar works during the preceding seven years ending the last day of the month previous to the bid publication month, satisfying either of the following tiers: three similar completed works each costing not less than 40% of the estimated contract cost, two similar completed works each costing not less than 50%, or one similar completed work costing not less than 80% of the project valuation.
• Bank Solvency Certification: Submission of an authentic banker's solvency certificate or credit facility letter issued by an RBI-scheduled commercial bank for an amount not less than 40% of the estimated project expenditure, issued within six months prior to the bid closing date.
• Net Worth & Working Capital: The bidding firm must demonstrate a positive net worth in each of the preceding three financial years, coupled with verifiable liquid working capital lines sufficient to finance continuous site operations without cash-flow interruptions.
• Statutory Registration & Blacklisting Covenant: Valid Goods and Services Tax (GSTIN) registration, permanent PAN allotment, EPFO and ESIC employer registrations, and a notarized non-conviction affidavit confirming that the bidding firm has not been debarred or blacklisted by any Central/State Ministry, PSU, or multilateral financing institution.

GFR 2017 Bidding Architecture, EMD / PBG Rules & MSME Safeguards

Bidding compliance is strictly governed under Rule 170 and Rule 171 of General Financial Rules 2017, the Public Procurement Policy for MSEs Order 2012, and the Make in India Preference Orders:

Public Procurement (Make in India) Purchase Preference Policy

In accordance with Department for Promotion of Industry and Internal Trade (DPIIT) statutory orders, purchase preference is accorded to local suppliers based on established domestic content metrics:

• Class-I Local Supplier: Goods, services, or civil works possessing local value addition of 50% or higher. Eligible for purchase preference within a margin of 20% over the L1 quote if the non-local vendor quotes lowest.
• Class-II Local Supplier: Local value addition between 20% and 50%. Entitled to participate in public bidding but not eligible for Make in India purchase preference bands.
• Non-Local Supplier: Local value addition below 20%. Excluded from domestic procurement tenders valued under Rs. 200 Crore where Global Tender Enquiries (GTE) are restricted by Central Government policy.
• Local Content Self-Certification: Bidders must submit statutory declarations detailing local sourcing, domestic assembly points, and value addition percentages, certified by statutory auditors for contracts exceeding Rs. 10 Crore.

Two-Envelope Bidding Protocol & Technical Evaluation Workflow

1. Digital Certificate Setup: Bidders must obtain a Class-III Digital Signature Certificate (DSC) with signing and encryption capability from an authorized Certifying Authority (CCA) registered under the Information Technology Act.
2. Cover-I: Fee & Technical Eligibility Envelope: Upload digital proof of tender document fee, EMD receipt (or Udyam MSE exemption certificate), CA turnover audits, work completion credentials, equipment schedules, key personnel CVs, and signed technical specifications compliance schedule.
3. Cover-II: Commercial Financial Bid (BoQ): Submit the Bill of Quantities (BoQ) spreadsheet indicating unit rates, applicable GST rates, and total landed project quotation. Unconditional price proposals must be digitally encrypted prior to submission cutoff.
4. Technical Bid Opening & Comparative Analysis: The tender evaluation committee decrypts and scrutinizes Cover-I submissions against mandatory qualifying criteria. Only technically compliant bidders qualify for financial bid decryption.
5. Financial Evaluation & Award of Contract (AoC): Cover-II financial bids of technically qualified vendors are opened publicly. The Lowest Responsive Bidder (L1) is issued the formal Letter of Award (LoA) following committee approval, PBG confirmation, and contract execution.

Contract Execution, Milestone Billing, Price Variation (PVC) & Arbitration

Contracts awarded by Eprocure operate under standardized General Conditions of Contract (GCC) and Special Conditions of Contract (SCC), providing well-defined operational safeguards:

• Running Account (RA) Billing: Payments are released based on certified milestone achievements and measured site progress verified by the designated Engineer-in-Charge, with statutory withholdings for TDS under Income Tax Act, GST TDS (2%), and labor welfare cess (1%).
• Price Variation Clause (PVC): For contracts with an execution tenure exceeding 12 to 18 months, price adjustment clauses index material costs (cement, steel, bitumen, POL) and labor rates to wholesale price indices published by the Reserve Bank of India and Ministry of Labour.
• Liquidated Damages (LD): In cases of contractor-attributed execution delays, liquidated damages are levied at 0.5% of contract value per week of unexcused delay, capped at a statutory ceiling of 10% of total awarded contract value.
• Dispute Resolution & Arbitration: Contractual disputes are subject to amicable resolution through Conciliation Committees. Unresolved disputes proceed to statutory arbitration under the Arbitration and Conciliation Act, 1996, with proceedings seated within the legal jurisdiction of National Jurisdiction.

Integrity Pact & CVC Anti-Collusion Governance Standards

Public procurement by Eprocure is reinforced through an Integrity Pact signed between the procuring authority and prospective vendors. Supervised by independent External Monitors (IEMs) appointed in consultation with the Central Vigilance Commission, the pact legally binds all parties against restrictive practices, bid-rigging, cartelization, or illicit inducements.

Bids exhibiting front-loaded pricing structures or abnormally low tender (ALT) values trigger comprehensive rate analysis audits. Vendors submitting unsubstantiated abnormally low bids are required to provide additional performance guarantees or risk summary disqualification in accordance with CVC circulars.

Cover-I Technical Bid Compilation & Compliance Audit Framework

Compiling an unassailable Technical Envelope (Cover-I) requires meticulous documentation to navigate scrutiny by the public procurement tender evaluation committee:

• Power of Attorney & Board Resolutions: Submission of an authentic, non-revocable Power of Attorney executed on judicial stamp paper of requisite value, duly notarized and supported by certified corporate board resolutions authorizing the designated signatory to digitally sign and bind the bidding firm.
• Chartered Accountant UDIN Certification: All financial turnover certificates, working capital statements, and net worth computations must bear the unique 18-digit Unique Document Identification Number (UDIN) generated by a practicing Chartered Accountant, without which financial credentials are automatically deemed invalid.
• Client Performance & Completion Certificates: Work experience must be corroborated through formal completion certificates signed by an officer not below the rank of Executive Engineer, Superintending Engineer, or General Manager. Certificates must explicitly mention agreement number, scope of work, date of award, scheduled completion date, actual completion date, and final billing amount.
• Technical Specification Compliance Schedule: Bidders must submit a clause-by-clause compliance matrix endorsing every technical parameter specified in the tender document. Deviations must be explicitly tabulated in the prescribed non-compliance schedule; unstated omissions discovered during technical evaluation result in bid rejection.
• OEM Authorization Formats (MAF): For supply and equipment packages, authorized dealers or system integrators must submit authentic Manufacturer Authorization Forms (MAF) directly from the Original Equipment Manufacturer guaranteeing warranty compliance, spare parts availability for 5 to 10 years, and back-to-back technical support.

Cover-II Financial Bid Structuring, BoQ Rules & Landed Cost Mechanics

Preparation of the commercial financial quotation in Cover-II determines the final ranking of responsive bidders and award of contract:

• Item-Rate & Percentage BoQ Modalities: Commercial proposals are submitted via encrypted spreadsheets where bidders quote item rates or an overall percentage above/below the estimated tender cost. Quotations must strictly exclude conditional rebates or ambiguous price qualification statements.
• GST & Statutory Taxation Transparency: The BoQ structure clearly distinguishes the ex-works base price from freight, transit insurance, and applicable Goods and Services Tax (GST). Evaluation of L1 rank is determined based on the net landed cost to Eprocure, taking into consideration eligible input tax credit (ITC) benefits under Indian taxation statutes.
• Abnormally Low Tender (ALT) Scrutiny: Where a commercial quotation is more than 20% below the departmental estimate, the procurement authority invokes CVC guidelines requiring the bidder to justify rate viability with detailed rate analysis. Failure to substantiate cost feasibility may warrant additional performance security or contract annulment.
• Reverse Auction Protocols (e-RA): In tenders incorporating electronic Reverse Auctions, qualified bidders compete on the portal in real time. The auction window typically operates for 60 to 120 minutes, with auto-extensions triggered if bids are received within the concluding five minutes of the auction clock.

Post-Award Execution, Quality Assurance (QA/QC) & Milestone Monitoring

Upon formal issuance of the Letter of Award (LoA), project implementation shifts to strict contract management and engineering oversight:

• Work Program & Milestone Schedules: Within 14 to 21 days of LoA, the contractor must submit a comprehensive baseline CPM/PERT network schedule delineating critical path milestones, resource deployment curves, and plant mobilization plans for administrative approval.
• Quality Control & Third-Party Inspection: All construction materials, structural fabrications, and mechanical supplies undergo rigorous factory acceptance tests (FAT) and site laboratory trials certified by accredited third-party inspection agencies (TPIA) such as RITES, SGS, or CEIL prior to permanent incorporation into works.
• Measurement Book Recording & Statutory Deductions: Execution progress is formally entered in statutory Measurement Books (MB) certified by the designated site engineer. Running payments are released after withholding mandatory statutory deductions: Income Tax TDS (Section 194C), GST TDS (2%), and Building and Other Construction Workers Welfare Cess (1%).
• Defect Liability Period (DLP) & Security Release: The awarded contractor remains legally obligated to rectify any latent defects, structural deficiencies, or operational faults occurring throughout the 12 to 36 month Defect Liability Period. Final retention money and PBG instruments are released only upon issuance of the Final Defect Clearance Certificate.

Banning, Debarment & Blacklisting Regulations under CVC Directives

To protect sovereign public funds, Eprocure strictly enforces the procurement debarment framework codified by the Ministry of Finance and Central Vigilance Commission. Vendors found engaging in collusive bidding, submitting forged credentials, abandoning awarded works, or violating the Code of Integrity face statutory debarment across all Central Government Ministries and PSUs for periods ranging from one to three years, following the issuance of formal show-cause notices and natural justice hearings.

Procurement Frequently Asked Questions & Bidder Guidelines